KISIWA TECHNICAL TRAINING INSTITUTE TENDER NOTICE

Kisiwa Technical Training Institute invites tenders from registered contractors in relevant categories and trade for the following works.
1. Completion of Tuition Block Phase U Tender No. KISTTI/PHTI/2011 -2012. Contractors must be registered with the Ministry of Public Works in category 'D' and above arid must pay a non-refundable fee of Ksh.5000/ = in cash for purchase of tender documents between gam-4pm from Monday to Friday. The bid security for works will be Ksh.200, 000/=.
Interested Contractors who appear in current Building Contractors register (Proof of registration required) may obtain Tender documents from the ProcurementiAccounts Offices at Kisiwa Technical Training Institute, Bungoma Central District in person or against a written application and upon production of payment receipt.
Interested bidders should note that only those meeting the criteria indicated below as minimum and supported by relevant documents at submission will be considered for fUrther evaluation.
I) Proof of works of similar magnitude and complexity undertaken in the last five years.
2) The bid bond must be informed of bank guarantee from a reputable bank only.
3) Adequate equipment and key personnel for the specified types of works.
4) Proof of sound financial standing and adequate access to bank credit lines.
5) Litigation History of the Company (both court and arbitration).
6) Confidential business questionnaire.
7) Tax Compliance Certificate.
The following tenders from Tenderers shall be considered NON RESPONSIVE and therefore subject to automatic disqualification.
a) A tender from a tenderer whose ongoing project(s) are behind Schedule and without any approved extension of time.
b) A tender from a tenderer who has been served with default notice on on-going project(s) or terminated in previous projects.
Completed tender documents should be sealed in plain envelops clearly marked tender reference number. Should be addressed to the undersigned or be deposited in the tender box
On or before 19 October, 2011 at 10.00 am. Tenders will be opened soon after closing in the Boardroom in the presence of bidder's representatives. Late bids will be returned unopened.
THE PRINCIPAL,
KISIWA TECHNICAL TRAININING INSTITUTE,
P.O.BOX 657-50200,
BUNGOMA.
The Institute reserves the right to accept or reject any tender application and is not obliged to give reasdns thereof, and does not bind itself to accept the lowest or any tender
RO. BOX 657-50200 Bungoma-Kenya
Cell Phone: 0712 22542210752 682891
E-maiI:kisiwainstitute@yahoo.com